Acceptance of Terms
By accessing and using Animas Deck Builders & Remodeling's services and website, you accept and agree to be bound by the terms and provision of this agreement. If you do not agree to be bound by these Terms of Service, you may not use this website or our services.
Services Description
Animas Deck Builders & Remodeling provides outdoor construction and remodeling services including but not limited to:
- Patio construction and installation
- Deck building and renovation
- Gazebo and pergola construction
- Outdoor kitchen installation
- Landscape lighting installation
- General outdoor structure repairs and maintenance
All services are provided by qualified professionals with appropriate experience and training in their respective fields.
Estimates and Quotes
Estimates provided by Animas Deck Builders & Remodeling are based on the information available at the time and are subject to change based on:
- Site conditions discovered during project execution
- Material availability and pricing changes
- Permitting requirements and fees
- Additional work requested by the customer
- Unforeseen circumstances or site conditions
Permits and Inspections
Animas Deck Builders & Remodeling will obtain all necessary permits required for the work to be performed, unless otherwise agreed upon in writing. The customer is responsible for any fees associated with permits and inspections. The customer agrees to allow access to the property for inspection purposes by relevant authorities.
Payment Terms
Payment for services is due as follows:
- 30% deposit required to schedule work
- 40% due upon delivery of materials to the site
- 30% due upon completion of work
Payment methods accepted include cash, check, and major credit cards. A 1.5% processing fee applies to credit card payments. Payments are due within 3 business days of invoice date.
Cancellations and Changes
Customer cancellations made more than 14 days prior to the scheduled start date will receive a full refund of any deposits paid. Cancellations made within 14 days of the scheduled start date will result in forfeiture of the deposit. Animas Deck Builders & Remodeling reserves the right to cancel any project for any reason and will provide a full refund of all payments made.
Project Timeline
Project completion dates are estimates only and are not assured. Animas Deck Builders & Remodeling will make reasonable efforts to complete projects within the estimated timeframe. Delays may occur due to:
- Weather conditions
- Material delivery delays
- Permitting delays
- Customer-requested changes
- Site conditions
- Other factors beyond our control
Quality Commitment
Animas Deck Builders & Remodeling provides a limited quality commitment on workmanship for a period of 2 years from the date of project completion. This commitment covers defects in workmanship but does not cover:
- Normal wear and tear
- Damage caused by improper maintenance
- Damage caused by acts of nature
- Damage caused by third parties
- Material defects (covered by manufacturer commitments)
Quality claims must be submitted in writing within 30 days of discovering the defect.
Customer Responsibilities
Customers agree to:
- Provide clear access to the work area
- Remove any obstacles or personal property from the work area
- Maintain existing utilities and ensure they are operational
- Provide necessary information about the property
- Make timely payments as outlined in this agreement
- Obtain any necessary homeowner association approvals
Liability and Insurance
Animas Deck Builders & Remodeling maintains appropriate liability insurance and workers' compensation coverage. The customer agrees to maintain property insurance covering the structure and contents during the project period. Animas Deck Builders & Remodeling is not responsible for damage to personal property left in the work area.
Intellectual Property
All designs, plans, and specifications created by Animas Deck Builders & Remodeling remain the property of Animas Deck Builders & Remodeling unless otherwise agreed in writing. Customers may not use these materials for other projects or with other contractors without written authorization.
Dispute Resolution
Any disputes arising from this agreement will be resolved through mediation in La Plata County, Colorado. If mediation is unsuccessful, disputes may be resolved through the court system in La Plata County, Colorado. The prevailing party in any legal action may recover reasonable attorney's fees and costs.
Limitation of Liability
Animas Deck Builders & Remodeling's liability for any claim arising out of or related to this agreement shall not exceed the total amount paid by the customer for the services. In no event shall Animas Deck Builders & Remodeling be liable for any indirect, incidental, special, or consequential damages, including but not limited to loss of profits, loss of use, or damage to adjacent property.
Force Majeure
Animas Deck Builders & Remodeling shall not be liable for any failure or delay in performance of work due to events beyond our reasonable control, including but not limited to acts of God, natural disasters, war, terrorism, civil unrest, labor disputes, material shortages, or government actions.
Entire Agreement
This agreement constitutes the entire understanding between the parties and supersedes all prior discussions, agreements, and understandings. This agreement may only be modified in writing signed by both parties.
Severability
If any provision of these Terms of Service is found to be invalid or unenforceable, the remaining provisions shall remain in full force and effect.
Contact Information
For questions about these Terms of Service, please contact us:
- By email: brodiecoln@adekbuilders.com
- By phone: (970) 247-3102
- By mail: 77 Mountain Top Rd, Durango, CO, 81303-7698